Exhibition Design Services for Norwich Castle
Norfolk County Council wishes to enter into a contract to provide Exhibition Design Services for the Norwich Castle Keep Development.
United Kingdom-Norwich: Museum-exhibition services
Section I: Contracting authority
I.1)Name and addresses
County Hall, Martineau Lane
Contact person: Julie Ward
NUTS code: UKH13
I.4)Type of the contracting authority
Section II: Object
‘Norwich Castle: Gateway to Medieval England’ Exhibition Design Services for Norwich Castle Keep Development.
II.1.2)Main CPV code
II.1.3)Type of contract
Contract to provide Exhibition Design Services for Norwich Castle Keep Development. Norwich Castle: Gateway to Medieval England Project.
II.1.6)Information about lots
II.2.2)Additional CPV code(s)
II.2.3)Place of performance
II.2.4)Description of the procurement:
Norfolk County Council wishes to enter into a contract to provide Exhibition Design Services for the Norwich Castle Keep Development. Norwich Castle: Gateway to Medieval England Project.
II.2.7)Duration of the contract, framework agreement or dynamic purchasing system
II.2.10)Information about variants
II.2.11)Information about options
II.2.13)Information about European Union funds
Phase 1 — Desired completion date for RIBA Stage 3 is 31.12.2017 — 1st major milestone date.
Phase 2 — The indicative date for completion is 31.3.2020. The award of Phase 2 will be subject to the successful award of 2nd-round funding from the Heritage Lottery Fund.
Section III: Legal, economic, financial and technical information
III.1.2)Economic and financial standing
III.1.3)Technical and professional ability
III.2.3)Information about staff responsible for the performance of the contract
Section IV: Procedure
IV.1.1)Type of procedure
IV.1.8)Information about the Government Procurement Agreement (GPA)
IV.2.1)Previous publication concerning this procedure
IV.2.2)Time limit for receipt of tenders or requests to participate
IV.2.4)Languages in which tenders or requests to participate may be submitted:
IV.2.7)Conditions for opening of tenders
Section VI: Complementary information
VI.1)Information about recurrence
This procurement will be managed electronically via the Council’s e-procurement system. To participate in this procurement, applicants must first be registered on the system at https://in-tendhost.co.uk/norfolkcc Full instructions for registration and use of the system can be found athttps://in-tendhost.co.uk/norfolkcc/aspx/BuyerProfiles Once registered you will be able to see the procurement project under the ‘tenders’ section and ‘express an interest’ to view the documentation. If you encounter any difficulties whilst using the system you can contact the In-tend support team by phoning +44 8442728810 or e-mailing email@example.com
The Public Contracts Regulations 2015 (as amended) provide for aggrieved parties who have been harmed or are at risk of harm by a breach of the rules to take action in the High Court (England, Wales and Northern EN Standard form 02 — Contract notice 12 / 19 Ireland). Proceedings must be brought within 30 days from the date of knowledge (the date on which the economic operator first knew or ought to have known that grounds for starting the proceedings had arisen) unless the Court considers that there is good reason for extending the period within which proceedings may be brought, in which case the Court may extend that period up to a maximum of 3 months from the date of knowledge.
VI.5)Date of dispatch of this notice: